Search
Close this search box.

Supplier terms and conditions

1.      Interpretation

The following definitions and rules of interpretation apply in these Conditions.

1.1    Definitions:

Business Day: a day other than a Saturday, Sunday or public holiday in England, when banks in London are open for business.

Commencement Date: has the meaning given in clause 2.2.

Conditions: these terms and conditions as amended from time to time in accordance with clause 18.9.

Contract: the contract between the Customer and the Supplier for the supply of Goods and/or Services in accordance with these Conditions.

Control: has the meaning given in section 1124 of the Corporation Tax Act 2010, and the expression change of Control shall be construed accordingly.

Customer: Marston (Holdings) Ltd registered in England and Wales with company number 04305487.

Customer Materials: has the meaning set out in clause 5.3(i).

Data Protection Legislation: the UK Data Protection Legislation and any other European Union legislation relating to personal data and all other legislation and regulatory requirements in force from time to time which apply to a party relating to the use of personal data (including, without limitation, the privacy of electronic communications); and the guidance and codes of practice issued by the relevant data protection or supervisory authority and applicable to a party.

Deliverables: all documents, products and materials developed by the Supplier or its agents, contractors and employees as part of or in relation to the Services in any form or media, including drawings, maps, plans, diagrams, designs, pictures, computer programs, data, specifications and reports (including drafts).

Delivery Location: has the meaning given in clause 4.2(b).

Goods: the goods (or any part of them) set out in the Order.

Goods Specification: any specification for the Goods, including any related plans and drawings, that is agreed in writing by the Customer and the Supplier.

Intellectual Property Rights: patents, utility models, rights to inventions, copyright and neighbouring and related rights, moral rights, trade marks and service marks, business names and domain names, rights in get-up and trade dress, goodwill and the right to sue for passing off or unfair competition, rights in designs, rights in computer software, database rights, rights to use, and protect the confidentiality of, confidential information (including know-how and trade secrets), and all other intellectual property rights, in each case whether registered or unregistered and including all applications and rights to apply for and be granted, renewals or extensions of, and rights to claim priority from, such rights and all similar or equivalent rights or forms of protection which subsist or will subsist now or in the future in any part of the world.

Mandatory Policies: the Customer’s business policies.

Order: in the Customer’s purchase order form, or in the Customer’s written acceptance of the Supplier’s quotation, or overleaf, as the case may be.

Services: the services, including any Deliverables, to be provided by the Supplier under the Contract as set out in the Service Specification.

Service Specification: the description or specification for Services agreed in writing by the Customer and the Supplier.

Supplier: the person or firm from whom the Customer purchases the Goods and/or Services.

UK Data Protection Legislation: all applicable data protection and privacy legislation in force from time to time in the UK including the General Data Protection Regulation ((EU) 2016/679); the Data Protection Act 2018; the Privacy and Electronic Communications Directive (2002/58/EC) (as updated by Directive 2009/136/EC) and the Privacy and Electronic Communications Regulations 2003 (SI 2003/2426) as amended.

1.2    Interpretation:

(a) A person includes a natural person, corporate or unincorporated body (whether or not having separate legal personality).

(b) A reference to a party includes its personal representatives, successors and permitted assigns.

(c) A reference to a statute or statutory provision is a reference to it as amended or re-enacted. A reference to a statute or statutory provision includes all subordinate legislation made under that statute or statutory provision.

(d) Any words following the terms including, include, in particular, for example or any similar expression shall be construed as illustrative and shall not limit the sense of the words, description, definition, phrase or term preceding those terms.

(e) A reference to writing or written includes email.

2.      Basis of contract

2.1       The Order constitutes an offer by the Customer to purchase Goods and/or Services from the Supplier in accordance with these Conditions.

2.2       The Order shall be deemed to be accepted on the earlier of:

(a) the Supplier issuing written acceptance of the Order; or

(b) any act by the Supplier consistent with fulfilling the Order,

at which point and on which date the Contract shall come into existence (Commencement Date).

2.3       These Conditions apply to the Contract to the exclusion of any other terms that the Supplier seeks to impose or incorporate, or which are implied by law, trade custom, practice or course of dealing.

2.4       All of these Conditions shall apply to the supply of both Goods and Services except where the application to one or the other is specified.

 

3.      Supply of Goods

3.1       The Supplier shall ensure that the Goods shall:

(a) correspond with their description and any applicable Goods Specification;

(b) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979) and fit for any purpose held out by the Supplier or made known to the Supplier by the Customer, expressly or by implication, and in this respect the Customer relies on the Supplier’s skill and judgement;

(c) where they are manufactured products, be free from defects in design, materials and workmanship and remain so for 12 months after delivery; and

(d) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Goods.

3.2       The Supplier shall ensure that at all times it has and maintains all the licences, permissions, authorisations, consents and permits that it needs to carry out its obligations under the Contract in respect of the Goods.

3.3       The Customer may inspect and test the Goods at any time before delivery. The Supplier shall remain fully responsible for the Goods despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier’s obligations under the Contract.

3.4       If following such inspection or testing the Customer considers that the Goods do not comply or are unlikely to comply with the Supplier’s undertakings at clause 3.1, the Customer shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.

3.5       The Customer may conduct further inspections and tests after the Supplier has carried out its remedial actions.

 

4.      Delivery of Goods

4.1       The Supplier shall ensure that:

(a) the Goods are properly packed and secured in such manner as to enable them to reach their destination in good condition;

(b) each delivery of the Goods is accompanied by a delivery note which shows the date of the Order, the Order number (if any), the type and quantity of the Goods (including the code number of the Goods (where applicable)), special storage instructions (if any) and, if the Goods are being delivered by instalments, the outstanding balance of Goods remaining to be delivered; and

(c) it states clearly on the delivery note any requirement for the Customer to return any packaging material for the Goods to the Supplier. Any such packaging material shall only be returned to the Supplier at the cost of the Supplier.

4.2       The Supplier shall deliver the Goods:

(a) on the date specified in the Order or, if no such date is specified, then within 14 days of the date of the Order;

(b) to the Customer’s premises at Kestrel House, Falconry Court, Bakers Street, Epping, Essex, CM16 5DQ or such other location as is set out in the Order or as instructed by the Customer before delivery (Delivery Location); and

(c) during the Customer’s normal hours of business on a Business Day, or as instructed by the Customer.

 

4.3       Delivery of the Goods shall be completed on the completion of unloading of the Goods at the Delivery Location.

4.4       If the Supplier:

(a) delivers less than 95% of the quantity of Goods ordered, the Customer may reject the Goods; and

(b) if the supplier has not delivered the remaining quatity of Goods within two weeks after the delivery, or

(c) delivers more than 105% of the quantity of Goods ordered, the Customer may at its sole discretion reject the Goods or the excess Goods,

and any rejected Goods shall be returnable at the Supplier’s risk and expense. If the Supplier delivers more or less than the quantity of Goods ordered, and the Customer accepts the delivery, the Supplier shall make a pro rata adjustment to the invoice for the Goods.

The Supplier shall not deliver the Goods in instalments without the Customer’s prior written consent. Where it is agreed that the Goods are delivered by instalments, they may be invoiced and paid for separately. However, failure by the Supplier to deliver any one instalment on time or at all or any defect in an instalment shall entitle the Customer to the remedies set out in clause 6.1.

Title and risk in the Goods shall pass to the Customer on completion of delivery.

5.      Supply of Services

5.1       The Supplier shall from date set out in the Order and for the duration of the Contract supply the Services to the Customer in accordance with the terms of the Contract.

5.2       The Supplier shall meet any performance dates for the Services specified in the Order or that the Customer notifies to the Supplier and time is of the essence in relation to any of those performance dates.

5.3       In providing the Services, the Supplier shall:

(a) co-operate with the Customer in all matters relating to the Services, and comply with all instructions of the Customer;

(b) perform the Services with the best care, skill and diligence in accordance with best practice in the Supplier’s industry, profession or trade;

(c) use personnel who are suitably skilled and experienced to perform tasks assigned to them, and in sufficient number to ensure that the Supplier’s obligations are fulfilled in accordance with the Contract;

(d) ensure that the Services will conform with all descriptions, standards and specifications set out in the Service Specification, and that the Deliverables shall be fit for any purpose that the Customer expressly or impliedly makes known to the Supplier;

(e) provide all equipment, tools and vehicles and such other items as are required to provide the Services;

(f) use the best quality goods, materials, standards and techniques, and ensure that the Deliverables, and all goods and materials supplied and used in the Services or transferred to the Customer, will be free from defects in workmanship, installation and design;

(g) obtain and at all times maintain all licences and consents which may be required for the provision of the Services;

(h) observe all health and safety rules and regulations and any other security requirements that apply at any of the Customer’s premises;

(i) hold all materials, equipment and tools, drawings, specifications and data supplied by the Customer to the Supplier (Customer Materials) in safe custody at its own risk, maintain the Customer Materials in good condition until returned to the Customer, and not dispose or use the Customer Materials other than in accordance with the Customer’s written instructions or authorisation; and

(j) not do or omit to do anything which may cause the Customer to lose any licence, authority, consent or permission upon which it relies for the purposes of conducting its business, and the Supplier acknowledges that the Customer may rely or act on the Services.

6.      Customer remedies

6.1       If the Supplier fails to deliver the Goods by the applicable date or to perform the Services by the applicable date, or both, the Customer shall, without limiting or affecting other rights or remedies available to it, have one or more of the following rights and remedies:

(a) to terminate the Contract with immediate effect by giving written notice to the Supplier;

(b) to refuse to accept any subsequent performance of the Services and/or delivery of the Goods which the Supplier attempts to make;

(c) to recover from the Supplier any costs incurred by the Customer in obtaining substitute goods and/or services from a third party;

(d) to require a refund from the Supplier of sums paid in advance for Services that the Supplier has not provided and/or Goods that it has not delivered; and

(e) to claim damages for any additional costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier’s failure to meet such dates.

6.2       If the Goods are not delivered by the applicable date or the Services are not performed by the applicable date, or both, the Customer may, at its option, claim or deduct 10% of the price of the Goods for each week’s delay in delivery of the Goods and/or claim or deduct 10% of the price of the Services for each week’s delay in performance of the Services, in each case by way of liquidated damages, until the earlier of delivery of the Goods or performance of the Services, as applicable, or termination or abandonment of the Contract by the Customer, up to a maximum of 50% of the total price of the Goods (in respect of late delivery of the Goods) and up to a maximum of 50% of the total price of the Services (in respect of late performance of the Services). If the Customer exercises its rights in respect of late delivery under this clause 6.2 it shall not be entitled to any of the remedies set out in clause 6.1 in respect of the late delivery of the Goods. If the Customer exercises its rights in respect of late performance under this clause 6.2 it shall not be entitled to any of the remedies set out in clause 6.1 in respect of the late performance of the Services.

6.3       If the Supplier has delivered Goods that do not comply with the undertakings set out in clause 3.1, then, without limiting or affecting other rights or remedies available to it, the Customer shall have one or more of the following rights and remedies, whether or not it has accepted the Goods:

(a) to terminate the Contract with immediate effect by giving written notice to the Supplier;

(b) to reject the Goods (in whole or in part) whether or not title has passed and to return them to the Supplier at the Supplier’s own risk and expense;

(c) to require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods (if paid);

(d) to refuse to accept any subsequent delivery of the Goods which the Supplier attempts to make;

(e) to recover from the Supplier any expenditure incurred by the Customer in obtaining substitute goods from a third party; and

(f) to claim damages for any additional costs, loss or expenses incurred by the Customer arising from the Supplier’s failure to supply Goods in accordance with clause 3.1.

6.4       If the Supplier has supplied Services that do not comply with the requirements of clause 5.3(d) then, without limiting or affecting other rights or remedies available to it, the Customer shall have one or more of the following rights and remedies:

(a) to terminate the Contract with immediate effect by giving written notice to the Supplier;

(b) to return the Deliverables to the Supplier at the Supplier’s own risk and expense;

(c) to require the Supplier to provide repeat performance of the Services, or to provide a full refund of the price paid for the Services (if paid);

(d) to refuse to accept any subsequent performance of the Services which the Supplier attempts to make;

(e) to recover from the Supplier any expenditure incurred by the Customer in obtaining substitute services or deliverables from a third party; and

(f) to claim damages for any additional costs, loss or expenses incurred by the Customer arising from the Supplier’s failure to comply with clause 5.3(d).

These Conditions shall extend to any substituted or remedial services and/or repaired or replacement goods supplied by the Supplier.

The Customer’s rights and remedies under the Contract are in addition to, and not exclusive of, any rights and remedies implied by statute and common law.

7.      Customer’s obligations

7.1       The Customer shall:

(a) provide the Supplier with reasonable access at reasonable times to the Customer’s premises for the purpose of providing the Services; and,

(b) provide such necessary information for the provision of the Services as the Supplier may reasonably request.

8.      Charges and payment

8.1       The price for the Goods:

(a) shall be the price set out in the Order, or if no price is quoted, the price set out in the Supplier’s published price list in force at the Commencement Date; and

(b) shall be inclusive of the costs of packaging, insurance and carriage of the Goods. No extra charges shall be effective unless agreed in writing and signed by the Customer.

8.2       The charges for the Services shall be set out in the Order, and shall be the full and exclusive remuneration of the Supplier in respect of the performance of the Services. Unless otherwise agreed in writing by the Customer, the charges shall include every cost and expense of the Supplier directly or indirectly incurred in connection with the performance of the Services.

8.3       In respect of the Goods, the Supplier shall invoice the Customer on or at any time after completion of delivery. In respect of Services, the Supplier shall invoice the Customer on completion of the Services. Each invoice shall include such supporting information required by the Customer to verify the accuracy of the invoice, including but not limited to the relevant purchase order number.

8.4       In consideration of the supply of Goods and/or Services by the Supplier, the Customer shall pay the invoiced amounts within 30 days of the date of a correctly rendered invoice to a bank account nominated in writing by the Supplier.

8.5       All amounts payable by the Customer under the Contract are exclusive of amounts in respect of valued added tax chargeable from time to time (VAT). Where any taxable supply for VAT purposes is made under the Contract by the Supplier to the Customer, the Customer shall, on receipt of a valid VAT invoice from the Supplier, pay to the Supplier such additional amounts in respect of VAT as are chargeable on the supply of the Goods and/or Services at the same time as payment is due for the supply of the Goods and/or Services.

8.6       If a party fails to make any payment due to the other party under the Contract by the due date for payment, then the defaulting party shall pay interest on the overdue sum from the due date until payment of the overdue sum, whether before or after judgment. Interest under this clause will accrue each date at 4% a year above the Bank of England’s base rate from time to time, but at 4% a year for any period when the base rate is below 0%.

8.7       The Supplier shall maintain complete and accurate records of the time spent and materials used by the Supplier in providing the Services, and the Supplier shall allow the Customer to inspect such records at all reasonable times on request.

8.8       The Customer may at any time, without notice to the Supplier, set off any liability of the Supplier to the Customer against any liability of the Customer to the Supplier, whether either liability is present or future, liquidated or unliquidated, and whether or not either liability arises under the Contract. If the liabilities to be set off are expressed in different currencies, the Customer may convert either liability at a market rate of exchange for the purpose of set-off. Any exercise by the Customer of its rights under this clause shall not limit or affect any other rights or remedies available to it under the Contract or otherwise.

9.      Intellectual property rights

9.1       All Intellectual Property Rights in or arising out of or in connection with the Services (other than Intellectual Property Rights in any Customer Materials) shall be owned by the Supplier.

9.2       The Supplier grants to the Customer, or shall procure the direct grant to the Customer of, a fully paid-up, worldwide, non-exclusive, royalty-free licence during the term of the Contract to copy and modify the Deliverables (excluding Customer Materials) for the purpose of receiving and using the Services and the Deliverables.

9.3       The Customer shall not sub-license, assign or otherwise transfer the rights granted by clause 9.2.

9.4       The Customer grants the Supplier a fully paid-up, non-exclusive, royalty-free non-transferable licence to copy any materials provided by the Customer to the Supplier for the term of the Contract for the purpose of providing the Services to the Customer.

9.5       All Customer Materials are the exclusive property of the Customer.

10.    Indemnity

10.1    The Supplier shall indemnify the Customer against all liabilities, costs, expenses, damages and losses (including but not limited to any direct, indirect or consequential losses, loss of profit, loss of reputation and all interest, penalties and legal costs (calculated on a full indemnity basis) and all other reasonable professional costs and expenses) suffered or incurred by the Customer arising out of or in connection with:

(a) any claim made against the Customer for actual or alleged infringement of a third party’s intellectual property rights arising out of, or in connection with, the manufacture, supply or use of the Goods, or receipt, use or supply of the Services (excluding the Customer Materials);

(b) any claim made against the Customer by a third party for death, personal injury or damage to property arising out of, or in connection with, defects in the Goods, as delivered, or the Deliverables; and

(c) any claim made against the Customer by a third party arising out of or in connection with the supply of the Goods, as delivered, or the Services.

10.2    This clause 10 shall survive termination of the Contract.

11.    Insurance

11.1    During the term of the Contract the Supplier shall maintain in force, with a reputable insurance company, professional indemnity insurance, product liability insurance and public liability insurance to cover the liabilities that may arise under or in connection with the Contract, and shall, on the Customer’s request, produce both the insurance certificate giving details of cover and the receipt for the current year’s premium in respect of each insurance.

12.    Confidentiality

12.1    Each party undertakes that it shall not at any time during the Contract and for a period of five years after termination of the Contract, disclose to any person any confidential information concerning the business, affairs, customers, clients or suppliers of the other party, except as permitted by clause 12.2.

12.2    Each party may disclose the other party’s confidential information:

(a) to its employees, officers, representatives or advisers who need to know such information for the purposes of exercising the party’s rights or carrying out its obligations under the Contract. Each party shall ensure that its employees, officers, representatives or advisers to whom it discloses the other party’s confidential information comply with this clause 12; and

(b) as may be required by law, a court of competent jurisdiction or any governmental or regulatory authority.

12.3    Neither party shall use the other party’s confidential information for any purpose other than to exercise its rights and perform its obligations under or in connection with the Contract.

13.    Compliance with relevant laws and policies

13.1    In performing its obligations under the Contract, the Supplier shall:

(a) comply with all applicable laws, statutes, regulations and codes from time to time in force; and

(b) comply with the Mandatory Policies.

14.    Data protection

14.1    Both parties will comply with all applicable requirements of the Data Protection Legislation. This clause 14 in addition to, and does not relieve, remove or replace, a party’s obligations or rights under the Data Protection Legislation. In this clause 14, Applicable Laws means (for so long as and to the extent that they apply to the Supplier) the law of the European Union, the law of any member state of the European Union and/or Domestic UK Law; and Domestic UK Law means the UK Data Protection Legislation and any other law that applies in the UK.

14.2    The parties acknowledge that for the purposes of the Data Protection Legislation, the Customer is the controller and the Supplier is the processor.

14.3    Without prejudice to the generality of clause 14.1, the Customer will ensure that it has all necessary appropriate consents and notices in place to enable lawful transfer of the personal data to the Supplier for the duration and purposes of the Contract.

14.4    Without prejudice to the generality of clause 14.1, the Supplier shall, in relation to any personal data processed in connection with the performance by the Supplier of its obligations under the Contract:

(a) process that personal data only on the documented written instructions of the Customer unless the Supplier is required by Applicable Laws to otherwise process that personal data. Where the Supplier is relying on Applicable Laws as the basis for processing personal data, the Supplier shall promptly notify the Customer of this before performing the processing required by the Applicable Laws unless those Applicable Laws prohibit the Supplier from so notifying the Customer;

(b) ensure that it has in place appropriate technical and organisational measures, reviewed and approved by the Customer, to protect against unauthorised or unlawful processing of personal data and against accidental loss or destruction of, or damage to, personal data, appropriate to the harm that might result from the unauthorised or unlawful processing or accidental loss, destruction or damage and the nature of the data to be protected, having regard to the state of technological development and the cost of implementing any measures (those measures may include, where appropriate, pseudonymising and encrypting personal data, ensuring confidentiality, integrity, availability and resilience of its systems and services, ensuring that availability of and access to personal data can be restored in a timely manner after an incident, and regularly assessing and evaluating the effectiveness of the technical and organisational measures adopted by it);

(c) ensure that all personnel who have access to and/or process personal data are obliged to keep the personal data confidential; and

(d) not transfer any personal data outside of the European Economic Area unless the prior written consent of the Customer has been obtained and the following conditions are fulfilled:

(i) the Customer or the Supplier has provided appropriate safeguards in relation to the transfer;

(ii) the data subject (as defined in the Data Protection Legislation) has enforceable rights and effective legal remedies;

(iii) the Supplier complies with its obligations under the Data Protection Legislation by providing an adequate level of protection to any personal data that is transferred; and

(iv) the Supplier complies with reasonable instructions notified to it in advance by the Customer with respect to the processing of the personal data;

(e) assist the Customer, at the Customer’s cost, in responding to any request from a data subject and in ensuring compliance with its obligations under the Data Protection Legislation with respect to security, breach notifications, impact assessments and consultations with supervisory authorities or regulators;

(f) notify the Customer without undue delay on becoming aware of a personal data breach;

(g) at the written direction of the Customer, delete or return personal data and copies thereof to the Customer on termination of the Contract unless required by Applicable Law to store the personal data; and

(h) maintain complete and accurate records and information to demonstrate its compliance with this clause 14 and allow for audits by the Customer or the Customer’s designated auditor and immediately inform the Customer if, in the opinion of the Supplier, an instruction infringes the Data Protection Legislation.

14.5    The Customer does not consent to the Supplier appointing any third party processor of personal data under the Contract.

14.6    Either party may, at any time on not less than 30 days’ notice, revise this clause 14 by replacing it with any applicable controller to processor standard clauses or similar terms forming part of an applicable certification scheme (which shall apply when replaced by attachment to the Contract).

15.    Termination

15.1    Without affecting any other right or remedy available to it, the Customer may terminate the Contract:

(a) with immediate effect by giving written notice to the Supplier if:

(i) there is a change of Control of the Supplier; or

(ii) the Supplier commits a breach of clause 13 (Compliance with relevant laws and policies).

(b) for convenience by giving the Supplier 1 months’ written notice.

15.2    Without affecting any other right or remedy available to it, either party may terminate the Contract with immediate effect by giving written notice to the other party if:

(a) the other party commits a material breach of any term of the Contract which breach is irremediable or (if such breach is remediable) fails to remedy that breach within a period of 21 days after being notified in writing to do so;

(b) the other party takes any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), obtaining a moratorium, being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business or, if the step or action is taken in another jurisdiction, in connection with any analogous procedure in the relevant jurisdiction;

(c) the other party suspends, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of its business; or

(d) the other party’s financial position deteriorates so far as to reasonably justify the opinion that its ability to give effect to the terms of this agreement is in jeopardy.

16.    Consequences of termination

16.1    On termination of the Contract, the Supplier shall immediately deliver to the Customer all Deliverables whether or not then complete, and return all Customer Materials. If the Supplier fails to do so, then the Customer may enter the Supplier’s premises and take possession of them. Until they have been returned or delivered, the Supplier shall be solely responsible for their safe keeping and will not use them for any purpose not connected with the Contract.

16.2    Termination or expiry of the Contract shall not affect the parties’ rights and remedies that have accrued as at termination or expiry, including the right to claim damages in respect of any breach of the Contract which existed at or before the date of termination or expiry.

16.3    Any provision of the Contract that expressly or by implication is intended to come into or continue in force on or after termination or expiry of the Contract shall remain in full force and effect.

17     Force majeure

17.1    Neither party shall be in breach of the Contract nor liable for delay in performing, or failure to perform, any of its obligations under the Contract if such delay or failure result from events, circumstances or causes beyond its reasonable control. In such circumstances the affected party shall be entitled to a reasonable extension of the time for performing such obligations. If the period of delay or non-performance continues for 4 weeks the party not affected may terminate the Contract by giving 4 days’ written notice to the affected party.

18     General

18.1    Assignment and other dealings.

(a) The Customer may at any time assign, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with all or any of its rights and obligations under the Contract.

(b) The Supplier shall not assign, transfer, mortgage, charge, delegate, declare a trust over or deal in any other manner with any of its rights and obligations under the Contract without the prior written consent of the Customer.

18.2    Subcontracting. The Supplier may not subcontract any or all of its rights or obligations under the Contract without the prior written consent of the Customer. If the Customer consents to any subcontracting by the Supplier, the Supplier shall remain responsible for all the acts and omissions of its subcontractors as if they were its own.

18.3    Notices

(a) Any notice or other communication given to a party under or in connection with the Contract shall be in writing and shall be:

(i) delivered by hand or by pre-paid first-class post or other next working day delivery service at its registered office (if a company) or its principal place of business (in any other case); or

(ii) sent by email to the address supplied

(b) Any notice or communication shall be deemed to have been received:

(i) if delivered by hand, on signature of a delivery receipt;

(ii) if sent by pre-paid first-class post or other next working day delivery service, at 9.00 am on the second Business Day after posting or at the time recorded by the delivery service; and

(iii) if sent by email, at the time of transmission, or, if this time falls outside business hours in the place of receipt, when business hours resume. In this clause 18.3(b)(iii), business hours means 9.00am to 5.00pm Monday to Friday on a day that is not a public holiday in the place of receipt.

(c) This clause does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any arbitration or other method of dispute resolution.

18.4    Entire agreement. The Contract constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations and understandings between them, whether written or oral, relating to its subject matter.

18.5    Variation. Except as set out in these Conditions, no variation of the Contract, including the introduction of any additional terms and conditions, shall be effective unless it is agreed in writing and signed by the parties or their authorised representatives.

18.6    Governing law. The Contract, and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation shall be governed by and construed in accordance with the law of England and Wales.

18.7    Jurisdiction. Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.

Contact us

Make a payment

Other ways to pay Marston:

0333 320 1100

Marston - 24-hour automated payment line

0333 320 1822

Speak to Marston team to make a payment or to discuss your circumstances

Engage logo

For payments to Engage Services:

0333 3206 200

Speak to Engage Services team to make a payment

Customer support

Speak to Marston team to make a payment or discuss your circumstances:

0333 320 1822

Our opening hours are 8 AM to 8 PM Monday to Friday, 8 AM to 4 PM on Saturdays.

Contact by post:

It is always quicker and easier to contact us by phone or email. If you do need to send us anything in the post, please send it to:

Marston, PO Box 324,
Rossendale, BB4 0GE

To pay by post, send a postal order, cheque or banker’s draft, made payable to ‘Marston’ to the address above. Make sure that you write your name and our reference number on anything you send us and if sending us a payment, on the back of the postal order, cheque or banker’s draft so we know what the payment is for.

If you are an Engage Services customer,

click here for help,

or to speak to one of our team, call

0333 320 6200

.

If you have received a Penalty Charge Notice (PCN) you must follow the instructions on the reverse of the notice which contains full contact details for the applicable enforcing authority.

Transfer Up instruction form

This service allows you to apply for County Court Judgments to be transferred to the High Court for enforcement.

Writ of delivery instruction form

Our Enforcement Officers are well equipped and experienced in recovering all types of fixed assets whether it be a single car or fleet.

Money judgment enforcement form

We can enforce judgments obtained in the High Court and almost any judgment issued in the County Court.

Commercial forfeiture instruction form

Landlords may instruct us to take peaceful possession of their commercial property.

CRAR enforcement form

Instruct us to recover commercial rent arrears.

Trespasser removal enforcement form

We can handle the process quickly and resolutely. Our dedicated team will attend the scene on receipt of the warrant and effect eviction without delay.

Residential possession enforcement form

Instruct us for evicting residential tenants.

Process serving and tracing instruction form

We specialise in process serving throughout England and Wales. Court and legal documents are served on a same day-basis when required. We also undertake trace enquiries.

Employment Tribunal Enforcement Form

Instruct us to enforce employment tribunal awards. We can apply to the court to register the award as a Judgment.

European Enforcement Order Instruction Form

If you have a Judgment from a Country outside of the Jurisdiction of England and Wales but where the Debtor resides in England and Wales then we can assist you.

New business enquiry - Marston Holdings

Get in touch with our specialist team

New business enquiry - ParkTrade

Get in touch with our specialist team

New business enquiry - Engage

Get in touch with our specialist team

New business enquiry - NSL

Get in touch with our specialist team

New business enquiry - Videalert

Get in touch with our specialist team

Debt recovery and enforcement services

Client support

Scott and Co logo

For more information

Scott & Co (Scotland) LLP

9 Melville Crescent Edinburgh, EH3 7LZ

0333 3206 871

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

ParkTrade logo

For more information

ParkTrade Europe AB

Sturegatan 16, 114 36 Stockholm, Sweden

+46 8 663 54 00

Business enquiries

+44 333 3202 985

Media enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Marston Holdings Logo

For more information

Marston Holdings

Rutland House, 8th Floor, 148 Edmund street, Birmingham, B3 2JR.

0333 3203 355

Business enquiries

0333 3202 985

Media enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Marston Holdings Logo

For more information

Marston High Court

5th Floor, 148 Great Charles Street, Queensway, Birmingham, B3 3HT

0333 3202 549

Business enquiries

Contact by post:

5th Floor, 148 Great Charles Street, Queensway
Birmingham, B3 3HT
DX 13014 Birmingham.

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Engage logo

For more information

Engage

Wavell House, Holcombe Road, Rossendale BB4 4NB

0333 320 6200

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

NSL logo

For more information

NSL Limited

12th Floor, One America Square, London, EC3N 2LS

If you have received a Penalty Charge Notice (PCN) you must follow the instructions on the reverse of the notice which contains full contact details for the applicable enforcing authority.

0333 3203 355

Business enquiries

NSL checking - Identity Verification Service

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Videalert logo

For more information

Videalert Limited

The Clock House, 87 Paines Lane, Pinner, Middlesex, HA5 3BY

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.

Client support

Project Centre logo

For more information

Project Centre Limited

0330 1358 950

Business enquiries

Business enquiries form

Use our online form and a member of our team will be in touch as soon as possible.